AB50: Bill Text

AB50,599,16 1. Pay an individual performing the work described in sub. (4) less than the prevailing wage rate in the same or most similar trade or occupation determined under this subsection.

AB50,599,21 2. Allow an individual performing the work described in sub. (4) to work a greater number of hours per day or per week than the prevailing hours of labor, unless the contractor, subcontractor, or contractor’s or subcontractor’s agent pays the individual for all hours worked in excess of the prevailing hours of labor at a rate of at least 1.5 times the individual’s hourly basic rate of pay.

AB50,600,4 (4) Covered employees. (a) Subject to par. (b), any person subject to this section shall pay all of the following employees the prevailing wage rate determined under sub. (3) and may not allow such employees to work a greater number of hours per day or per week than the prevailing hours of labor, unless the person pays the employee for all hours worked in excess of the prevailing hours of labor at a rate of at least 1.5 times the employee’s hourly basic rate of pay:

AB50,600,6 1. All laborers, workers, mechanics, and truck drivers employed on the site of a project of public works that is subject to this section.

AB50,600,12 2. All laborers, workers, mechanics, and truck drivers employed in the manufacturing or furnishing of materials, articles, supplies, or equipment on the site of a project of public works that is subject to this section or from a facility dedicated exclusively, or nearly so, to a project of public works that is subject to this section by a contractor, subcontractor, agent, or other person performing any work on the site of the project.

AB50,600,20 (b) A laborer, worker, mechanic, or truck driver who is employed to process, manufacture, pick up, or deliver materials or products from a commercial establishment that has a fixed place of business from which the establishment supplies processed or manufactured materials or products or from a facility that is not dedicated exclusively, or nearly so, to a project of public works that is subject to this section is not entitled to receive the prevailing wage rate determined under sub. (3) or to receive at least 1.5 times his or her hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor unless any of the following applies:

AB50,601,2 1. The laborer, worker, mechanic, or truck driver is employed to go to the source of mineral aggregate such as sand, gravel, or stone and deliver that mineral aggregate to the site of a project of public works that is subject to this section by depositing the material directly in final place, from the transporting vehicle or through spreaders from the transporting vehicle.

AB50,601,6 2. The laborer, worker, mechanic, or truck driver is employed to go to the site of a project of public works that is subject to this section, pick up excavated material or spoil from the site of the project, and transport that excavated material or spoil away from the site of the project.

AB50,601,8 (c) A person subject to this section shall pay a truck driver who is an owner- operator of a truck separately for his or her work and for the use of his or her truck.

AB50,601,9 (5) Nonapplicability. This section does not apply to any of the following:

AB50,601,16 (a) A single-trade project of public works for which the estimated project cost of completion is less than $48,000, a multiple-trade project of public works for which the estimated project cost of completion is less than $100,000, or, in the case of a multiple-trade project of public works erected, constructed, repaired, remodeled, or demolished by a private contractor for a city or village having a population of less than 2,500 or for a town, a multiple-trade project of public works for which the estimated project cost of completion is less than $234,000.

AB50,601,20 (b) Work performed on a project of public works for which the local governmental unit contracting for the project is not required to compensate any contractor, subcontractor, contractor’s or subcontractor’s agent, or individual for performing the work.

AB50,601,22 (c) Minor service or maintenance work, warranty work, or work under a supply and installation contract.

AB50,602,2 (f) A project of public works involving the erection, construction, repair, remodeling, or demolition of a residential property containing 2 dwelling units or less.

AB50,602,8 (g) A road, street, bridge, sanitary sewer, or water main project that is a part of a development in which not less than 90 percent of the lots contain or will contain 2 dwelling units or less, as determined by the local governmental unit at the time of approval of the development, and that, on completion, is acquired by, or dedicated to, a local governmental unit, including under s. 236.13 (2), for ownership or maintenance by the local governmental unit.

AB50,602,14 (8) Posting. A local governmental unit that has contracted for a project of public works shall post the prevailing wage rates determined by the department, the prevailing hours of labor, and the provisions of subs. (10) (a) and (11) (a) in at least one conspicuous place on the site of the project that is easily accessible by employees working on the project, or, if there is no common site on the project, at the place normally used by the local governmental unit to post public notices.

AB50,602,23 (9) Compliance. (a) When the department finds that a local governmental unit has not requested a determination under sub. (3) (am) or that a local governmental unit, contractor, or subcontractor has not physically incorporated a determination into a contract or subcontract as required under this section or has not notified a minor subcontractor of a determination in the manner prescribed by the department by rule promulgated under sub. (3) (dm), the department shall notify the local governmental unit, contractor, or subcontractor of the noncompliance and shall file the determination with the local governmental unit, contractor, or subcontractor within 30 days after the notice.

AB50,603,5 (b) Upon completion of a project of public works and before receiving final payment for his or her work on the project, each agent or subcontractor shall furnish the contractor with an affidavit stating that the agent or subcontractor has complied fully with the requirements of this section. A contractor may not authorize final payment until the affidavit is filed in proper form and order.

AB50,603,20 (c) Upon completion of a project of public works and before receiving final payment for his or her work on the project, each contractor shall file with the local governmental unit authorizing the work an affidavit stating that the contractor has complied fully with the requirements of this section and that the contractor has received an affidavit under par. (b) from each of the contractor’s agents and subcontractors. A local governmental unit may not authorize a final payment until the affidavit is filed in proper form and order. If a local governmental unit authorizes a final payment before an affidavit is filed in proper form and order or if the department determines, based on the greater weight of the credible evidence, that any person performing the work specified in sub. (4) has been or may have been paid less than the prevailing wage rate or less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor and requests that the local governmental unit withhold all or part of the final payment, but the local governmental unit fails to do so, the local governmental unit is liable for all back wages payable up to the amount of the final payment.

AB50,604,4 (10) Records; inspection; enforcement. (a) Each contractor, subcontractor, or contractor’s or subcontractor’s agent that performs work on a project of public works that is subject to this section shall keep full and accurate records clearly indicating the name and trade or occupation of every individual performing the work described in sub. (4) and an accurate record of the number of hours worked by each of those individuals and the actual wages paid for the hours worked.

AB50,604,13 (b) The department or the contracting local governmental unit may demand and examine, and every contractor, subcontractor, and contractor’s or subcontractor’s agent shall keep, and furnish upon request by the department or local governmental unit, copies of payrolls and other records and information relating to the wages paid to individuals performing the work described in sub. (4) for work to which this section applies. The department may inspect records in the manner provided in ch. 103. Every contractor, subcontractor, or agent performing work on a project of public works that is subject to this section is subject to the requirements of ch. 103 relating to the examination of records.

AB50,605,4 (c) If requested by any person, the department shall inspect the payroll records of any contractor, subcontractor, or agent performing work on a project of public works that is subject to this section as provided in this paragraph to ensure compliance with this section. On receipt of such a request, the department shall request that the contractor, subcontractor, or agent submit to the department a certified record of the information specified in par. (a), other than personally identifiable information relating to an employee of the contractor, subcontractor, or agent, for no longer than a 4-week period. The department may request that a contractor, subcontractor, or agent submit those records no more than once per calendar quarter for each project of public works on which the contractor, subcontractor, or agent is performing work. The department may not charge a requester a fee for obtaining that information. Certified records submitted to the department under this paragraph are open for public inspection and copying under s. 19.35 (1).

AB50,605,10 (d) Section 103.005 (5) (f), (11), (12), and (13) applies to this section, except that s. 103.005 (12) (a) does not apply to a person who fails to provide any information to the department to assist the department in determining prevailing wage rates under sub. (3) (am) or (ar). Section 111.322 (2m) applies to discharge and other discriminatory acts arising in connection with any proceeding under this section, including proceedings under sub. (11) (a).

AB50,605,17 (11) Liability and penalties. (a) 1. A contractor, subcontractor, or contractor’s or subcontractor’s agent who fails to pay the prevailing wage rate determined by the department under sub. (3) or who pays less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor is liable to any affected employee in the amount of his or her unpaid wages or his or her unpaid overtime compensation and in an additional amount as liquidated damages as provided under subd. 2. or 3., whichever is applicable.

AB50,606,3 2. If the department determines upon inspection under sub. (10) (b) or (c) that a contractor, subcontractor, or contractor’s or subcontractor’s agent has failed to pay the prevailing wage rate determined by the department under sub. (3) or has paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor, the department shall order the contractor to pay to any affected employee the amount of his or her unpaid wages or his or her unpaid overtime compensation and an additional amount equal to 100 percent of the amount of those unpaid wages or that unpaid overtime compensation as liquidated damages within a period specified by the department in the order.

AB50,606,15 3. In addition to or in lieu of recovering the liability specified in subd. 1. as provided in subd. 2., any employee for and on behalf of that employee and other employees similarly situated may commence an action to recover that liability in any court of competent jurisdiction. If the court finds that a contractor, subcontractor, or contractor’s or subcontractor’s agent has failed to pay the prevailing wage rate determined by the department under sub. (3) or has paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor, the court shall order the contractor, subcontractor, or agent to pay to any affected employee the amount of his or her unpaid wages or his or her unpaid overtime compensation and an additional amount equal to 100 percent of the amount of those unpaid wages or that unpaid overtime compensation as liquidated damages.

AB50,606,20 5. No employee may be a party plaintiff to an action under subd. 3. unless the employee consents in writing to become a party and the consent is filed in the court in which the action is brought. Notwithstanding s. 814.04 (1), the court shall, in addition to any judgment awarded to the plaintiff, allow reasonable attorney fees and costs to be paid by the defendant.

AB50,607,2 (b) 1. Except as provided in subds. 2., 4., and 6., any contractor, subcontractor, or contractor’s or subcontractor’s agent who violates this section may be fined not more than $200 or imprisoned for not more than 6 months or both. Each day that any violation continues is a separate offense.

AB50,607,11 2. Whoever induces any individual who seeks to be or is employed on any project of public works that is subject to this section to give up, waive, or return any part of the wages to which the individual is entitled under the contract governing the project, or who reduces the hourly basic rate of pay normally paid to an individual for work on a project that is not subject to this section during a week in which the individual works both on a project of public works that is subject to this section and on a project that is not subject to this section, by threat not to employ, by threat of dismissal from employment, or by any other means is guilty of an offense under s. 946.15 (1).

AB50,607,21 3. Any individual employed on a project of public works that is subject to this section who knowingly allows a contractor, subcontractor, or contractor’s or subcontractor’s agent to pay him or her less than the prevailing wage rate set forth in the contract governing the project, who gives up, waives, or returns any part of the compensation to which he or she is entitled under the contract, or who gives up, waives, or returns any part of the compensation to which he or she is normally entitled for work on a project that is not subject to this section during a week in which the individual works both on a project of public works that is subject to this section and on a project that is not subject to this section, is guilty of an offense under s. 946.15 (2).

AB50,608,4 4. Whoever induces any individual who seeks to be or is employed on any project of public works that is subject to this section to allow any part of the wages to which the individual is entitled under the contract governing the project to be deducted from the individual’s pay is guilty of an offense under s. 946.15 (3), unless the deduction would be allowed under 29 CFR 3.5 or 3.6 from an individual who is working on a project that is subject to 40 USC 3142.

AB50,608,10 5. Any individual who is employed on a project of public works that is subject to this section who knowingly allows any part of the wages to which he or she is entitled under the contract governing the project to be deducted from his or her pay is guilty of an offense under s. 946.15 (4), unless the deduction would be allowed under 29 CFR 3.5 or 3.6 from an individual who is working on a project that is subject to 40 USC 3142.

AB50,608,13 6. Subdivision 1. does not apply to any person who fails to provide any information to the department to assist the department in determining prevailing wage rates under sub. (3) (am) or (ar).

AB50,609,3 (12) Debarment. (a) Except as provided under pars. (b) and (c), the department shall notify any local governmental unit applying for a determination under sub. (3) of the names of all persons that the department has found to have failed to pay the prevailing wage rate determined under sub. (3) or has found to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor at any time in the preceding 3 years. The department shall include with each name the address of the person and shall specify when the person failed to pay the prevailing wage rate and when the person paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor. A local governmental unit may not award any contract to the person unless otherwise recommended by the department or unless 3 years have elapsed from the date the department issued its findings or the date of final determination by a court of competent jurisdiction, whichever is later.

AB50,609,9 (b) The department may not include in a notification under par. (a) the name of any person on the basis of having subcontracted a contract for a project of public works to a person that the department has found to have failed to pay the prevailing wage rate determined under sub. (3) or has found to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor.

AB50,609,13 (c) This subsection does not apply to any contractor, subcontractor, or agent who in good faith commits a minor violation of this section, as determined on a case- by-case basis through administrative hearings with all rights to due process afforded to all parties or who has not exhausted or waived all appeals.

AB50,609,23 (d) Any person submitting a bid or negotiating a contract on a project of public works that is subject to this section shall, on the date the person submits the bid or negotiates the contract, identify any construction business in which the person, or a shareholder, officer, or partner of the person, if the person is a business, owns, or has owned at least a 25 percent interest on the date the person submits the bid or negotiates the contract or at any other time within 3 years preceding the date the person submits the bid or negotiates the contract, if the business has been found to have failed to pay the prevailing wage rate determined under sub. (3) or to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor.

AB50,610,1 (e) The department shall promulgate rules to administer this subsection.

AB50,1164 Section 1164. 66.10012 of the statutes is created to read:

AB50,610,3 66.10012 Workforce housing. (1) Definitions. In this section:

AB50,610,4 (a) “Housing agency” means the department of administration.

AB50,610,6 (b) “Housing grant” means any grant administered by the department of administration under s. 16.303 or 16.309.

AB50,610,7 (c) “Political subdivision” means any city, village, town, or county.

AB50,610,11 (d) “Workforce housing” means housing to which all of the following apply, as adjusted for family size and the county in which the household is located, based on the county’s 5-year average median income and housing costs as calculated by the U.S. bureau of the census in its American community survey:

AB50,610,13 1. The housing costs a household no more than 30 percent of the household’s gross median income.

AB50,610,16 2. The residential units of the housing are for initial occupancy by individuals whose household median income is no more than 120 percent of the county’s gross median income.

AB50,610,19 (2) Housing initiatives. (a) Subject to par. (b), to implement a workforce housing initiative, a political subdivision may enact an ordinance, adopt a resolution, or put into effect a policy to accomplish any of the following:

AB50,610,21 1. Reduce by at least 10 percent the processing time for all permits related to workforce housing.

AB50,610,23 2. Reduce by at least 10 percent the cost of impact fees that a political subdivision may impose on developments that include workforce housing units.

AB50,611,2 3. Reduce by at least 10 percent the parking requirements for developments that include workforce housing units.

AB50,611,4 4. Increase by at least 10 percent the allowable zoning density for developments that include workforce housing units.

AB50,611,6 5. Establish a mixed-use tax incremental district with at least 20 percent of the housing units to be used for workforce housing.

AB50,611,8 6. Demonstrate compliance with a housing affordability report under s. 66.10013.

AB50,611,10 7. Rehabilitate at least 5 dwelling units of existing, uninhabitable housing stock into habitable workforce housing.

AB50,611,13 8. Modify existing zoning ordinances to allow for the development of workforce housing in areas zoned for commercial or mixed-use development or in areas near employment centers or major transit corridors.

AB50,611,14 9. Extend the life of a tax incremental district under s. 66.1105 (6) (g) 1.

AB50,611,16 10. Reduce by at least 10 percent the cost of roads for developments that include workforce housing units.

AB50,611,18 11. Implement any other initiative to address the workforce housing needs of the political subdivision.

AB50,611,23 (b) After a political subdivision completes one of the actions specified in par. (a), the workforce housing initiative shall be considered in effect once the political subdivision submits to the department of administration a written explanation of how the action complies with the workforce housing initiative and posts the explanation on the political subdivision’s website.

AB50,612,10 (c) Once a political subdivision’s action takes effect under par. (b), its workforce housing initiative remains in effect for 5 years. A political subdivision may put into effect more than one of the workforce housing initiatives under par. (a). After June 30, 2026, if a political subdivision has in effect at the same time at least 3 of the workforce housing initiatives under par. (a), the housing agency shall give priority to housing grant applications from, or that relate to a project in, the political subdivision. The department of administration shall promulgate rules establishing how and based on what information the department will give priority to housing grant applications under this paragraph and prescribing the form of application for receiving priority.

AB50,1165 Section 1165. 66.1010 of the statutes is repealed.

AB50,1166 Section 1166. 66.1011 (1) of the statutes is amended to read:

AB50,613,3 66.1011 (1) Declaration of policy. The right of all persons to have equal opportunities for housing regardless of their sex, race, color, disability, as defined in s. 106.50 (1m) (g), sexual orientation, as defined in s. 111.32 (13m), religion, national origin, marital status, family status, as defined in s. 106.50 (1m) (k), status as a victim of domestic abuse, sexual assault, or stalking, as defined in s. 106.50 (1m) (u), lawful source of income, receipt of rental or housing assistance, as defined in s. 106.50 (1m) (rm), age, or ancestry is a matter both of statewide concern under ss. 101.132 and 106.50 and also of local interest under this section and s. 66.0125. The enactment of ss. 101.132 and 106.50 by the legislature does not preempt the subject matter of equal opportunities in housing from consideration by political subdivisions, and does not exempt political subdivisions from their duty, nor deprive them of their right, to enact ordinances that prohibit discrimination in any type of housing solely on the basis of an individual being a member of a protected class.

AB50,1167 Section 1167. 66.1011 (1) of the statutes, as affected by 2025 Wisconsin Act .... (this act), is amended to read:

AB50,613,20 66.1011 (1) Declaration of policy. The right of all persons to have equal opportunities for housing regardless of their sex, race, color, disability, as defined in s. 106.50 (1m) (g), sexual orientation, as defined in s. 111.32 (13m), religion, national origin, marital status, family status, as defined in s. 106.50 (1m) (k), status as a victim of domestic abuse, sexual assault, or stalking, as defined in s. 106.50 (1m) (u), status as a holder or nonholder of a license under s. 343.03 (3r), lawful source of income, receipt of rental or housing assistance, as defined in s. 106.50 (1m) (rm), age, or ancestry is a matter both of statewide concern under ss. 101.132 and 106.50 and also of local interest under this section and s. 66.0125. The enactment of ss. 101.132 and 106.50 by the legislature does not preempt the subject matter of equal opportunities in housing from consideration by political subdivisions, and does not exempt political subdivisions from their duty, nor deprive them of their right, to enact ordinances that prohibit discrimination in any type of housing solely on the basis of an individual being a member of a protected class.

AB50,1168 Section 1168. 66.1039 of the statutes is created to read:

AB50,613,22 66.1039 Transit authorities. (1) Definitions. In this section:

AB50,613,23 (a) “Authority” means a transit authority created under this section.

AB50,614,2 (b) “Bonds” means any bonds, interim certificates, notes, debentures, or other obligations of an authority issued under this section.

AB50,614,3 (c) “Common carrier” means any of the following:

AB50,614,4 1. A common motor carrier, as defined in s. 194.01 (1).

AB50,614,5 2. A contract motor carrier, as defined in s. 194.01 (2).

AB50,614,6 3. A railroad subject to ch. 195, as described in s. 195.02 (1) and (3).

AB50,614,7 4. A water carrier, as defined in s. 195.02 (5).

AB50,614,12 (d) “Comprehensive unified local transportation system” means a transportation system that is comprised of motor bus lines and any other local public transportation facilities, the major portion of which is located within, or the major portion of the service of which is supplied to the inhabitants of, the jurisdictional area of the authority.

AB50,614,14 (em) “Metropolitan area” means a metropolitan statistical area as designated by the U.S. office of management and budget.

AB50,614,15 (f) “Municipality” means any city, village, or town.

AB50,614,18 (g) “Participating political subdivision” means a political subdivision that is a member of an authority, either from the time of creation of the authority or by later joining the authority.

AB50,614,19 (h) “Political subdivision” means a municipality or county.

AB50,615,6 (i) “Transportation system” means all land, shops, structures, equipment, property, franchises, and rights of whatever nature required for transportation of passengers within the jurisdictional area of the authority and, only to the extent specifically authorized under this section, outside the jurisdictional area of the authority. “Transportation system” includes elevated railroads, subways, underground railroads, motor vehicles, motor buses, and any combination thereof, and any other form of mass transportation, but does not include transportation excluded from the definition of “common motor carrier” under s. 194.01 (1) or charter or contract operations to, from, or between points that are outside the jurisdictional area of the authority.

AB50,615,17 (2) Creation of transit authorities. (f) Statewide regional transit authorities. 1. Any 2 or more political subdivisions located within the same metropolitan area may jointly create a transit authority that is a public body corporate and politic and a separate governmental entity and that is known by a name that includes the words “regional transit authority,” if the governing body of each political subdivision adopts a resolution authorizing the political subdivision to become a member of the authority and all the resolutions are identical to each other. Except as provided in subd. 2. and sub. (13), once created, the members of the authority shall consist of all political subdivisions that adopt resolutions, as provided in this subdivision. Once created, the authority may transact business and exercise any powers granted to it under this section.

AB50,615,23 2. After an authority is created under subd. 1., any political subdivision located in whole or in part within a metropolitan area located in whole or in part within an authority’s jurisdiction may join the authority if the governing body of the political subdivision adopts a resolution identical to the existing resolutions of the authority’s participating political subdivisions and the authority’s board of directors approves the political subdivision’s joinder.

AB50,616,3 3. The jurisdictional area of an authority created under this paragraph is the geographic area formed by the combined territorial boundaries of all participating political subdivisions of the authority.

AB50,616,10 (3) Transit authority governance. (a) The powers of an authority shall be vested in its board of directors. Directors shall be appointed for 4-year terms. A majority of the board of directors’ full authorized membership constitutes a quorum for the purpose of conducting the authority’s business and exercising its powers. Action may be taken by the board of directors upon a vote of a majority of the directors present and voting, unless the bylaws of the authority require a larger number.

AB50,616,12 (fm) The board of directors of an authority created under sub. (2) (f) consists of the following members:

AB50,616,17 1. One member from each participating political subdivision that is a county, appointed by the county executive of each county and approved by the county board except that, if the county does not have an elected county executive, the member shall be appointed by the county board chairperson and approved by the county board.

AB50,616,22 2. One member from each of the two participating political subdivisions that are municipalities, if any, having the highest population, appointed by the mayor and approved by the common council or appointed by the village president and approved by the village board or appointed by the town board chairperson and approved by the town board, as applicable.

AB50,616,23 3. One member appointed by the governor.

AB50,617,9 4. Not more than 2 members from participating political subdivisions that are municipalities other than those identified under subd. 2., appointed by the mayor and approved by the common council or appointed by the village president and approved by the village board or appointed by the town board chairperson and approved by the town board, as applicable. If the authority opts to include members under this subdivision on the board of directors, the bylaws of the authority shall include a provision specifying a method by which the members appointed under this subdivision shall rotate among the participating political subdivisions not entitled to make an appointment under subd. 2.