Amendment SA1-SSA2-SB70

SB70-SSA2-SA1,71,6 (3) Prevailing wage rates and hours of labor. (am) A local governmental unit, before making a contract by direct negotiation or soliciting bids on a contract for the erection, construction, remodeling, repairing, or demolition of any project of public works, shall apply to the department to determine the prevailing wage rate for each trade or occupation required in the work contemplated. The department shall conduct investigations and hold public hearings as necessary to define the trades or occupations that are commonly employed on projects of public works that are subject to this section and to inform itself of the prevailing wage rates in all areas of the state for those trades or occupations, in order to determine the prevailing wage rate for each trade or occupation. The department shall issue its determination within 30 days after receiving the request and shall file the determination with the requesting local governmental unit.

SB70-SSA2-SA1,71,13 (ar) The department shall, by January 1 of each year, compile the prevailing wage rates for each trade or occupation in each area. The compilation shall, in addition to the current prevailing wage rates, include future prevailing wage rates when those prevailing wage rates can be determined for any trade or occupation in any area and shall specify the effective date of those future prevailing wage rates. If a project of public works extends into more than one area, the department shall determine only one standard of prevailing wage rates for the entire project.

SB70-SSA2-SA1,71,21 (av) In determining prevailing wage rates under par. (am) or (ar), the department may not use data from projects that are subject to this section, s. 103.49 or 103.50, or 40 USC 3142 unless the department determines that there is insufficient wage data in the area to determine those prevailing wage rates, in which case the department may use data from projects that are subject to this section, s. 103.49 or 103.50, or 40 USC 3142. In determining prevailing wage rates under par. (am) or (ar), the department may not use data from any construction work that is performed by a local governmental unit or a state agency.

SB70-SSA2-SA1,72,5 (bm) Any person may request a recalculation of any portion of an initial determination within 30 days after the initial determination date if the person submits evidence with the request showing that the prevailing wage rate for any given trade or occupation included in the initial determination does not represent the prevailing wage rate for that trade or occupation in the area. The evidence shall include wage rate information reflecting work performed by individuals working in the contested trade or occupation in the area during the current survey period. The department shall affirm or modify the initial determination within 15 days after the date on which the department receives the request for recalculation.

SB70-SSA2-SA1,72,19 (br) In addition to the recalculation under par. (bm), the local governmental unit that requested the determination under this subsection may request a review of any portion of a determination within 30 days after the date of issuance of the determination if the local governmental unit submits evidence with the request showing that the prevailing wage rate for any given trade or occupation included in the determination does not represent the prevailing wage rate for that trade or occupation in the city, village, or town in which the proposed project of public works is located. That evidence shall include wage rate information for the contested trade or occupation on at least 3 similar projects located in the city, village, or town where the proposed project of public works is located and on which some work has been performed during the current survey period and which were considered by the department in issuing its most recent compilation under par. (ar). The department shall affirm or modify the determination within 15 days after the date on which the department receives the request for review.

SB70-SSA2-SA1,73,7 (dm) A local governmental unit that is subject to this section shall include a reference to the prevailing wage rates determined by the department and to the prevailing hours of labor in the notice published for the purpose of securing bids for the project of public works. Except as otherwise provided in this paragraph, if any contract or subcontract for a project of public works is entered into, the prevailing wage rates determined by the department and the prevailing hours of labor shall be physically incorporated into and made a part of the contract or subcontract. For a minor subcontract, as determined by the department, the department shall prescribe by rule the method of notifying the minor subcontractor of the prevailing wage rates and prevailing hours of labor applicable to the minor subcontract. The prevailing wage rates and prevailing hours of labor applicable to a contract or subcontract may not be changed during the time that the contract or subcontract is in force.

SB70-SSA2-SA1,73,9 (e) No contractor, subcontractor, or contractor's or subcontractor's agent that is subject to this section may do any of the following:

SB70-SSA2-SA1,73,12 1. Pay an individual performing the work described in sub. (4) less than the prevailing wage rate in the same or most similar trade or occupation determined under this subsection.

SB70-SSA2-SA1,73,17 2. Allow an individual performing the work described in sub. (4) to work a greater number of hours per day or per week than the prevailing hours of labor, unless the contractor, subcontractor, or contractor's or subcontractor's agent pays the individual for all hours worked in excess of the prevailing hours of labor at a rate of at least 1.5 times the individual's hourly basic rate of pay.

SB70-SSA2-SA1,73,23 (4) Covered employees. (a) Subject to par. (b), any person subject to this section shall pay all of the following employees the prevailing wage rate determined under sub. (3) and may not allow such employees to work a greater number of hours per day or per week than the prevailing hours of labor, unless the person pays the employee for all hours worked in excess of the prevailing hours of labor at a rate of at least 1.5 times the employee's hourly basic rate of pay:

SB70-SSA2-SA1,73,25 1. All laborers, workers, mechanics, and truck drivers employed on the site of a project of public works that is subject to this section.

SB70-SSA2-SA1,74,6 2. All laborers, workers, mechanics, and truck drivers employed in the manufacturing or furnishing of materials, articles, supplies, or equipment on the site of a project of public works that is subject to this section or from a facility dedicated exclusively, or nearly so, to a project of public works that is subject to this section by a contractor, subcontractor, agent, or other person performing any work on the site of the project.

SB70-SSA2-SA1,74,14 (b) A laborer, worker, mechanic, or truck driver who is employed to process, manufacture, pick up, or deliver materials or products from a commercial establishment that has a fixed place of business from which the establishment supplies processed or manufactured materials or products or from a facility that is not dedicated exclusively, or nearly so, to a project of public works that is subject to this section is not entitled to receive the prevailing wage rate determined under sub. (3) or to receive at least 1.5 times his or her hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor unless any of the following applies:

SB70-SSA2-SA1,74,19 1. The laborer, worker, mechanic, or truck driver is employed to go to the source of mineral aggregate such as sand, gravel, or stone and deliver that mineral aggregate to the site of a project of public works that is subject to this section by depositing the material directly in final place, from the transporting vehicle or through spreaders from the transporting vehicle.

SB70-SSA2-SA1,74,23 2. The laborer, worker, mechanic, or truck driver is employed to go to the site of a project of public works that is subject to this section, pick up excavated material or spoil from the site of the project, and transport that excavated material or spoil away from the site of the project.

SB70-SSA2-SA1,75,3 (c) A person subject to this section shall pay a truck driver who is an owner-operator of a truck separately for his or her work and for the use of his or her truck.

SB70-SSA2-SA1,75,4 (5) Nonapplicability. This section does not apply to any of the following:

SB70-SSA2-SA1,75,11 (a) A single-trade project of public works for which the estimated project cost of completion is less than $48,000, a multiple-trade project of public works for which the estimated project cost of completion is less than $100,000, or, in the case of a multiple-trade project of public works erected, constructed, repaired, remodeled, or demolished by a private contractor for a city or village having a population of less than 2,500 or for a town, a multiple-trade project of public works for which the estimated project cost of completion is less than $234,000.

SB70-SSA2-SA1,75,15 (b) Work performed on a project of public works for which the local governmental unit contracting for the project is not required to compensate any contractor, subcontractor, contractor's or subcontractor's agent, or individual for performing the work.

SB70-SSA2-SA1,75,17 (c) Minor service or maintenance work, warranty work, or work under a supply and installation contract.

SB70-SSA2-SA1,75,20 (f) A project of public works involving the erection, construction, repair, remodeling, or demolition of a residential property containing 2 dwelling units or less.

SB70-SSA2-SA1,76,2 (g) A road, street, bridge, sanitary sewer, or water main project that is a part of a development in which not less than 90 percent of the lots contain or will contain 2 dwelling units or less, as determined by the local governmental unit at the time of approval of the development, and that, on completion, is acquired by, or dedicated to, a local governmental unit, including under s. 236.13 (2), for ownership or maintenance by the local governmental unit.

SB70-SSA2-SA1,76,8 (8) Posting. A local governmental unit that has contracted for a project of public works shall post the prevailing wage rates determined by the department, the prevailing hours of labor, and the provisions of subs. (10) (a) and (11) (a) in at least one conspicuous place on the site of the project that is easily accessible by employees working on the project, or, if there is no common site on the project, at the place normally used by the local governmental unit to post public notices.

SB70-SSA2-SA1,76,17 (9) Compliance. (a) When the department finds that a local governmental unit has not requested a determination under sub. (3) (am) or that a local governmental unit, contractor, or subcontractor has not physically incorporated a determination into a contract or subcontract as required under this section or has not notified a minor subcontractor of a determination in the manner prescribed by the department by rule promulgated under sub. (3) (dm), the department shall notify the local governmental unit, contractor, or subcontractor of the noncompliance and shall file the determination with the local governmental unit, contractor, or subcontractor within 30 days after the notice.

SB70-SSA2-SA1,76,22 (b) Upon completion of a project of public works and before receiving final payment for his or her work on the project, each agent or subcontractor shall furnish the contractor with an affidavit stating that the agent or subcontractor has complied fully with the requirements of this section. A contractor may not authorize final payment until the affidavit is filed in proper form and order.

SB70-SSA2-SA1,77,12 (c) Upon completion of a project of public works and before receiving final payment for his or her work on the project, each contractor shall file with the local governmental unit authorizing the work an affidavit stating that the contractor has complied fully with the requirements of this section and that the contractor has received an affidavit under par. (b) from each of the contractor's agents and subcontractors. A local governmental unit may not authorize a final payment until the affidavit is filed in proper form and order. If a local governmental unit authorizes a final payment before an affidavit is filed in proper form and order or if the department determines, based on the greater weight of the credible evidence, that any person performing the work specified in sub. (4) has been or may have been paid less than the prevailing wage rate or less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor and requests that the local governmental unit withhold all or part of the final payment, but the local governmental unit fails to do so, the local governmental unit is liable for all back wages payable up to the amount of the final payment.

SB70-SSA2-SA1,77,18 (10) Records; inspection; enforcement. (a) Each contractor, subcontractor, or contractor's or subcontractor's agent that performs work on a project of public works that is subject to this section shall keep full and accurate records clearly indicating the name and trade or occupation of every individual performing the work described in sub. (4) and an accurate record of the number of hours worked by each of those individuals and the actual wages paid for the hours worked.

SB70-SSA2-SA1,78,2 (b) The department or the contracting local governmental unit may demand and examine, and every contractor, subcontractor, and contractor's or subcontractor's agent shall keep, and furnish upon request by the department or local governmental unit, copies of payrolls and other records and information relating to the wages paid to individuals performing the work described in sub. (4) for work to which this section applies. The department may inspect records in the manner provided in ch. 103. Every contractor, subcontractor, or agent performing work on a project of public works that is subject to this section is subject to the requirements of ch. 103 relating to the examination of records.

SB70-SSA2-SA1,78,16 (c) If requested by any person, the department shall inspect the payroll records of any contractor, subcontractor, or agent performing work on a project of public works that is subject to this section as provided in this paragraph to ensure compliance with this section. On receipt of such a request, the department shall request that the contractor, subcontractor, or agent submit to the department a certified record of the information specified in par. (a), other than personally identifiable information relating to an employee of the contractor, subcontractor, or agent, for no longer than a 4-week period. The department may request that a contractor, subcontractor, or agent submit those records no more than once per calendar quarter for each project of public works on which the contractor, subcontractor, or agent is performing work. The department may not charge a requester a fee for obtaining that information. Certified records submitted to the department under this paragraph are open for public inspection and copying under s. 19.35 (1).

SB70-SSA2-SA1,78,22 (d) Section 103.005 (5) (f), (11), (12), and (13) applies to this section, except that s. 103.005 (12) (a) does not apply to a person who fails to provide any information to the department to assist the department in determining prevailing wage rates under sub. (3) (am) or (ar). Section 111.322 (2m) applies to discharge and other discriminatory acts arising in connection with any proceeding under this section, including proceedings under sub. (11) (a).

SB70-SSA2-SA1,79,4 (11) Liability and penalties. (a) 1. A contractor, subcontractor, or contractor's or subcontractor's agent who fails to pay the prevailing wage rate determined by the department under sub. (3) or who pays less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor is liable to any affected employee in the amount of his or her unpaid wages or his or her unpaid overtime compensation and in an additional amount as liquidated damages as provided under subd. 2. or 3., whichever is applicable.

SB70-SSA2-SA1,79,13 2. If the department determines upon inspection under sub. (10) (b) or (c) that a contractor, subcontractor, or contractor's or subcontractor's agent has failed to pay the prevailing wage rate determined by the department under sub. (3) or has paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor, the department shall order the contractor to pay to any affected employee the amount of his or her unpaid wages or his or her unpaid overtime compensation and an additional amount equal to 100 percent of the amount of those unpaid wages or that unpaid overtime compensation as liquidated damages within a period specified by the department in the order.

SB70-SSA2-SA1,79,24 3. In addition to or in lieu of recovering the liability specified in subd. 1. as provided in subd. 2., any employee for and on behalf of that employee and other employees similarly situated may commence an action to recover that liability in any court of competent jurisdiction. If the court finds that a contractor, subcontractor, or contractor's or subcontractor's agent has failed to pay the prevailing wage rate determined by the department under sub. (3) or has paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor, the court shall order the contractor, subcontractor, or agent to pay to any affected employee the amount of his or her unpaid wages or his or her unpaid overtime compensation and an additional amount equal to 100 percent of the amount of those unpaid wages or that unpaid overtime compensation as liquidated damages.

SB70-SSA2-SA1,80,5 5. No employee may be a party plaintiff to an action under subd. 3. unless the employee consents in writing to become a party and the consent is filed in the court in which the action is brought. Notwithstanding s. 814.04 (1), the court shall, in addition to any judgment awarded to the plaintiff, allow reasonable attorney fees and costs to be paid by the defendant.

SB70-SSA2-SA1,80,9 (b) 1. Except as provided in subds. 2., 4., and 6., any contractor, subcontractor, or contractor's or subcontractor's agent who violates this section may be fined not more than $200 or imprisoned for not more than 6 months or both. Each day that any violation continues is a separate offense.

SB70-SSA2-SA1,80,18 2. Whoever induces any individual who seeks to be or is employed on any project of public works that is subject to this section to give up, waive, or return any part of the wages to which the individual is entitled under the contract governing the project, or who reduces the hourly basic rate of pay normally paid to an individual for work on a project that is not subject to this section during a week in which the individual works both on a project of public works that is subject to this section and on a project that is not subject to this section, by threat not to employ, by threat of dismissal from employment, or by any other means is guilty of an offense under s. 946.15 (1).

SB70-SSA2-SA1,81,3 3. Any individual employed on a project of public works that is subject to this section who knowingly allows a contractor, subcontractor, or contractor's or subcontractor's agent to pay him or her less than the prevailing wage rate set forth in the contract governing the project, who gives up, waives, or returns any part of the compensation to which he or she is entitled under the contract, or who gives up, waives, or returns any part of the compensation to which he or she is normally entitled for work on a project that is not subject to this section during a week in which the individual works both on a project of public works that is subject to this section and on a project that is not subject to this section, is guilty of an offense under s. 946.15 (2).

SB70-SSA2-SA1,81,9 4. Whoever induces any individual who seeks to be or is employed on any project of public works that is subject to this section to allow any part of the wages to which the individual is entitled under the contract governing the project to be deducted from the individual's pay is guilty of an offense under s. 946.15 (3), unless the deduction would be allowed under 29 CFR 3.5 or 3.6 from an individual who is working on a project that is subject to 40 USC 3142.

SB70-SSA2-SA1,81,15 5. Any individual who is employed on a project of public works that is subject to this section who knowingly allows any part of the wages to which he or she is entitled under the contract governing the project to be deducted from his or her pay is guilty of an offense under s. 946.15 (4), unless the deduction would be allowed under 29 CFR 3.5 or 3.6 from an individual who is working on a project that is subject to 40 USC 3142.

SB70-SSA2-SA1,81,18 6. Subdivision 1. does not apply to any person who fails to provide any information to the department to assist the department in determining prevailing wage rates under sub. (3) (am) or (ar).

SB70-SSA2-SA1,82,6 (12) Debarment. (a) Except as provided under pars. (b) and (c), the department shall notify any local governmental unit applying for a determination under sub. (3) of the names of all persons that the department has found to have failed to pay the prevailing wage rate determined under sub. (3) or has found to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor at any time in the preceding 3 years. The department shall include with each name the address of the person and shall specify when the person failed to pay the prevailing wage rate and when the person paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor. A local governmental unit may not award any contract to the person unless otherwise recommended by the department or unless 3 years have elapsed from the date the department issued its findings or the date of final determination by a court of competent jurisdiction, whichever is later.

SB70-SSA2-SA1,82,12 (b) The department may not include in a notification under par. (a) the name of any person on the basis of having subcontracted a contract for a project of public works to a person that the department has found to have failed to pay the prevailing wage rate determined under sub. (3) or has found to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor.

SB70-SSA2-SA1,82,16 (c) This subsection does not apply to any contractor, subcontractor, or agent who in good faith commits a minor violation of this section, as determined on a case-by-case basis through administrative hearings with all rights to due process afforded to all parties or who has not exhausted or waived all appeals.

SB70-SSA2-SA1,83,2 (d) Any person submitting a bid or negotiating a contract on a project of public works that is subject to this section shall, on the date the person submits the bid or negotiates the contract, identify any construction business in which the person, or a shareholder, officer, or partner of the person, if the person is a business, owns, or has owned at least a 25 percent interest on the date the person submits the bid or negotiates the contract or at any other time within 3 years preceding the date the person submits the bid or negotiates the contract, if the business has been found to have failed to pay the prevailing wage rate determined under sub. (3) or to have paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor.

SB70-SSA2-SA1,83,3 (e) The department shall promulgate rules to administer this subsection.

SB70-SSA2-SA1,136 Section 136. 84.41 (3) of the statutes is created to read:

SB70-SSA2-SA1,83,9 84.41 (3) Employment regulations. Employment regulations set forth in s. 103.50 pertaining to wages and hours shall apply to all projects constructed under s. 84.40 in the same manner as such laws apply to projects on other state highways. Where applicable, the federal wages and hours law known as the Davis-Bacon act shall apply.

SB70-SSA2-SA1,137 Section 137. 84.54 of the statutes is repealed.

SB70-SSA2-SA1,138 Section 138. 86.51 of the statutes is repealed.

SB70-SSA2-SA1,139 Section 139. 102.125 (1m) of the statutes is created to read:

SB70-SSA2-SA1,83,21 102.125 (1m) Application and premium fraud. If an insurer has evidence that an application for worker's compensation insurance coverage is fraudulent or that an employer has committed fraud by misclassifying employees to lower the employer's worker's compensation insurance premiums in violation of s. 943.395, the insurer shall report the claim to the department. The department may require an insurer to investigate an allegedly fraudulent application or alleged fraud by misclassification of employees and may provide the insurer with any records of the department relating to that alleged fraud. An insurer that investigates alleged fraud under this subsection shall report the results of that investigation to the department.

SB70-SSA2-SA1,140 Section 140. 102.125 (2) of the statutes is amended to read:

SB70-SSA2-SA1,84,3 102.125 (2) Assistance by department of justice. The department of workforce development may request the department of justice to assist the department of workforce development in an investigation under sub. (1) or (1m) or in the investigation of any other suspected fraudulent activity on the part of an employer, employee, insurer, health care provider, or other person related to worker's compensation.

SB70-SSA2-SA1,141 Section 141. 102.125 (3) of the statutes is amended to read:

SB70-SSA2-SA1,84,10 102.125 (3) Prosecution. If based on an investigation under sub. (1), (1m), or (2) the department has a reasonable basis to believe that a violation of s. 943.20, 943.38, 943.39, 943.392, 943.395, 943.40, or any other criminal law has occurred, the department shall refer the results of the investigation to the department of justice or to the district attorney of the county in which the alleged violation occurred for prosecution.

SB70-SSA2-SA1,142 Section 142. 102.16 (4) of the statutes is amended to read:

SB70-SSA2-SA1,84,19 102.16 (4) The department and the division have jurisdiction to pass on any question arising out of sub. (3) and to order the employer to reimburse an employee or other person for any sum deducted from wages or paid by him or her in violation of that subsection. In addition to the any penalty provided in s. 102.85 (1), any employer violating sub. (3) shall be liable to an injured employee for the reasonable value of the necessary services rendered to that employee under any arrangement made in violation of sub. (3) without regard to that employee's actual disbursements for those services.

SB70-SSA2-SA1,143 Section 143. 102.17 (9) (a) 1. of the statutes is renumbered 102.17 (9) (a) 1m. and amended to read:

SB70-SSA2-SA1,84,25 102.17 (9) (a) 1m. “Fire fighter" means any person employed on a full-time basis by the state or any political subdivision as a member or officer of a fire department, including the 1st class cities and state fire marshal and deputies or an individual who volunteers as a member or officer of such a department.

SB70-SSA2-SA1,144 Section 144. 102.17 (9) (a) 1c. of the statutes is created to read:

SB70-SSA2-SA1,85,3 102.17 (9) (a) 1c. “Correctional officer” has the meaning given in s. 102.475 (8) (a).

SB70-SSA2-SA1,145 Section 145. 102.17 (9) (a) 1e. of the statutes is created to read:

SB70-SSA2-SA1,85,6 102.17 (9) (a) 1e. “Emergency medical responder” has the meaning given in s. 256.01 (4p).

SB70-SSA2-SA1,146 Section 146. 102.17 (9) (a) 1g. of the statutes is created to read:

SB70-SSA2-SA1,85,9 102.17 (9) (a) 1g. “Emergency medical services practitioner” has the meaning given in s. 256.01 (5).

SB70-SSA2-SA1,147 Section 147. 102.17 (9) (a) 1p. of the statutes is created to read:

SB70-SSA2-SA1,85,16 102.17 (9) (a) 1p. “Medicolegal investigation staff member" includes a chief deputy coroner, a deputy coroner, a deputy medical examiner, and any individual who assists the office of a coroner or medical examiner with an investigation of a death. “Medicolegal investigation staff member" does not include an individual performing solely administrative functions in the office of a coroner or medical examiner.

SB70-SSA2-SA1,148 Section 148. 102.17 (9) (b) (intro.) of the statutes is amended to read:

SB70-SSA2-SA1,85,25 102.17 (9) (b) (intro.) Subject to par. (c), in the case of a mental injury that is not accompanied by a physical injury and that results in a diagnosis of post-traumatic stress disorder in a law enforcement officer, as defined in s. 23.33 (1) (ig), an emergency medical responder, an emergency services practitioner, a correctional officer, a public safety answering point dispatcher, a coroner, a medical examiner, a medicolegal investigation staff member, or a fire fighter, the claim for compensation for the mental injury, in order to be compensable under this chapter, is subject to all of the following:

SB70-SSA2-SA1,149 Section 149. 102.75 (1m) of the statutes is amended to read:

SB70-SSA2-SA1,86,6 102.75 (1m) The moneys collected under subs. (1) and (1g) and under ss. 102.28 (2) and 102.31 (7), together with all accrued interest, shall constitute a separate nonlapsible fund designated as the worker's compensation operations fund. Moneys in the fund may be expended only as provided in ss. 20.427 (1) (ra) and 20.445 (1) (ra), (rb), and (rp), and (rr) and may not be used for any other purpose of the state.

SB70-SSA2-SA1,150 Section 150. 102.82 (2) (a) (intro.) of the statutes is amended to read:

SB70-SSA2-SA1,86,11 102.82 (2) (a) (intro.) Except as provided in pars. (ag), (am), and (ar), all for a 1st or 2nd determination by the department that an employer was uninsured, an uninsured employers employer shall pay to the department the greater of the following:

SB70-SSA2-SA1,151 Section 151. 102.82 (2) (ab) of the statutes is created to read:

SB70-SSA2-SA1,86,15 102.82 (2) (ab) Except as provided in pars. (ag), (am), and (ar), for a 3rd determination by the department that an employer was uninsured, an uninsured employer shall pay to the department the greater of the following:

SB70-SSA2-SA1,86,19 1. Three times the amount determined by the department to equal what the uninsured employer would have paid during periods of illegal nonpayment for worker's compensation in the preceding 3-year period, based on the employer's payroll in the preceding 3 years.

SB70-SSA2-SA1,86,20 2. Three thousand dollars.

SB70-SSA2-SA1,152 Section 152. 102.82 (2) (ad) of the statutes is created to read:

SB70-SSA2-SA1,86,24 102.82 (2) (ad) Except as provided in pars. (ag), (am), and (ar), for a 4th or subsequent determination by the department that an employer was uninsured, an uninsured employer shall pay to the department the greater of the following:

SB70-SSA2-SA1,87,4 1. Four times the amount determined by the department to equal what the uninsured employer would have paid during periods of illegal nonpayment for worker's compensation in the preceding 3-year period, based on the employer's payroll in the preceding 3 years.

SB70-SSA2-SA1,87,5 2. Four thousand dollars.

SB70-SSA2-SA1,153 Section 153. 102.82 (2) (am) of the statutes is amended to read:

SB70-SSA2-SA1,87,10 102.82 (2) (am) The department may waive any payment owed under par. (a), (ab), or (ad) by an uninsured employer if the department determines that the uninsured employer is subject to this chapter only because the uninsured employer has elected to become subject to this chapter under s. 102.05 (2) or 102.28 (2).

SB70-SSA2-SA1,154 Section 154. 102.82 (2) (ar) of the statutes is amended to read:

SB70-SSA2-SA1,87,17 102.82 (2) (ar) The department may waive any payment owed under par. (a), (ab), (ad), or (ag) or sub. (1) if the department determines that the sole reason for the uninsured employer's failure to comply with s. 102.28 (2) is that the uninsured employer was a victim of fraud, misrepresentation or gross negligence by an insurance agent or insurance broker or by a person whom a reasonable person would believe is an insurance agent or insurance broker.

SB70-SSA2-SA1,155 Section 155. 102.85 (1) of the statutes is repealed and recreated to read:

SB70-SSA2-SA1,87,22 102.85 (1) (a) If an employer has failed to comply with s. 102.16 (3) or 102.28 (2), the employer shall, for a first violation, forfeit the greater of $1,000 or the amount of the premium that would have been payable for each time the employer failed to comply with s. 102.16 (3) or 102.28 (3).

SB70-SSA2-SA1,88,2 (b) If an employer has failed to comply with s. 102.16 (3) or 102.28 (2), the employer shall, for a 2nd violation, forfeit the greater of $2,000 or 2 times the amount of the premium that would have been payable for each time the employer failed to comply with s. 102.16 (3) or 102.28 (3).

SB70-SSA2-SA1,88,6 (c) If an employer has failed to comply with s. 102.16 (3) or 102.28 (2), the employer shall, for a 3rd violation, forfeit the greater of $3,000 or 3 times the amount of the premium that would have been payable for each time the employer failed to comply with s. 102.16 (3) or 102.28 (3).