NR 747.30(1)(d)4.
4. State or municipal permits for installation of remedial equipment;
NR 747.30(1)(d)5.
5. Actual costs for the purchase or rental of temporary building structures of a size adequate to house remedial equipment; and
NR 747.30(1)(d)6.
6. Restoration or replacement of a private or public potable water supply.
NR 747.30(1)(e)
(e) Costs associated with personnel, travel and related expenses:
NR 747.30(1)(e)1.
1. Contractor or subcontractor costs for remedial action activities;
NR 747.30(1)(e)2.
2. Labor and fringe benefit costs associated with inspection and supervision other than specified in
subd. 4.;
NR 747.30(1)(e)3.
3. Actual costs incurred for travel and lodging which are not in excess of state travel rates; and
NR 747.30(1)(e)4.
4. Actual verified labor, fringe benefit and equipment costs when claimants use their own personnel or equipment to conduct a remediation.
NR 747.30 Note
Note: A listing of state travel and meal rates may be obtained by writing to the Wisconsin DNR, Bureau for Remediation & Redevelopment, P.O. Box 7921, Madison WI 53707-7921.
NR 747.30(1)(f)
(f) Costs associated with the preparation of a claim package under the scope of this chapter and other related costs:
NR 747.30(1)(f)1.
1. Fees up to $500 for a certified public accountant, contractor, or other independent preparer for compiling a claim under this chapter; and
NR 747.30(1)(f)2.
2. For an owner or operator only, compensation to third parties for bodily injury and property damage caused by a petroleum product discharge from an underground petroleum product storage tank system.
NR 747.30(1)(g)
(g) Costs associated with the support or protection of existing utilities or structures located within the remediation area during a remediation.
NR 747.30 Note
Note: Reimbursement for the re-installation of utilities or structures, without prior department approval, may not be made.
NR 747.30(2)
(2) Exclusions from eligible costs. The department has identified various costs determined to be ineligible for reimbursement. Section
292.63, Stats., lists specific cost items which may not be reimbursable under the PECFA program. In order to control costs and provide awards for the most cost-effective remediations of petroleum-contaminated sites within the scope of this chapter, the following costs may not be reimbursed:
NR 747.30(2)(a)
(a) Costs determined to be unrelated to remedial action activities under the scope of this chapter:
NR 747.30(2)(a)1.
1. Any costs not supported by cancelled checks or other absolute proof of payment at time of submittal;
NR 747.30(2)(a)2.
2. Any overtime labor charge, excluding an emergency action, billed at other than a straight time rate;
NR 747.30(2)(a)3.
3. Costs for contamination cleanups from non-residential heating oil or boiler tank systems and discharges from mobile fueling tanks or fuel storage tanks on vehicles;
NR 747.30(2)(a)4.
4. Costs associated with used oil remediations, if the oil is not from internal combustion engines;
NR 747.30(2)(a)5.
5. Costs associated with environmental audits, environmental reconnaissance or real estate transactions, construction projects, new construction or long-term loan transactions;
NR 747.30(2)(a)6.
6. Costs associated with investigation activities to locate petroleum product storage systems or home oil tank systems to determine eligibility for an award under the scope of this chapter;
NR 747.30(2)(a)7.
7. Costs incurred after the department determines that no further remedial action is required, except for abandonment of monitoring wells and finalization of site closure;
NR 747.30(2)(a)8.
8. Other costs that the department determines to be associated with, but not integral to, the remediation of a petroleum product discharge from a petroleum product storage system or home oil tank system.
NR 747.30(2)(b)
(b) Costs related to improper or incompetent remedial activities and services:
NR 747.30(2)(b)1.
1. Costs associated with incompetent or non-effective cleanup actions which were not based upon sound professional and scientific judgment;
NR 747.30(2)(b)2.
2. Costs of redoing remedial action activities or remedial action work which was incomplete or incompetent;
NR 747.30(2)(b)3.
3. Costs associated with rework on remedial systems to accommodate construction, upgrades, retrofits, or redevelopment projects;
NR 747.30(2)(b)4.
4. Any costs associated with actions that exceed the necessary activities to bring a site to the required level of remediation;
NR 747.30(2)(b)5.
5. Costs associated with the repair or replacement of damaged buildings, sewer lines, water lines, electrical lines, phone lines, fiber optic lines or other utilities on the property;
NR 747.30(2)(b)6.
6. Costs associated with the re-installation of damaged remedial equipment or the re-installation or modification of the remedial equipment for purposes other than effective remediation;
NR 747.30(2)(b)7.
7. Additional interest costs accrued due to improper or incomplete filing of claims or non-response to department requests for additional information, exceptions being delays caused by the department claim process;
NR 747.30(2)(b)9.
9. Any costs related to invoices or bills for which payment verification is unobtainable.
NR 747.30(2)(c)
(c) Costs for testing or sampling unrelated to the investigation for the extent of contamination under the scope of this chapter:
NR 747.30(2)(c)1.
1. Costs for sampling and testing for heavy metals, except lead testing when the discharge is verified to be from leaded gasoline, or lead and cadmium when the source is used motor oil;
NR 747.30(2)(c)2.
2. Costs associated with the analysis for inappropriate constituents not normally part of or associated with an eligible petroleum product even if required by the department; and
NR 747.30(2)(d)1.1. Costs for remedial action activities funded under
42 USC 6991, unless the owner or operator or the person owning the home oil tank system repays the funds provided under
42 USC 6991;
NR 747.30(2)(d)2.
2. Expenditures required by the department in order to meet the groundwater protection standards,
ch. 160, Stats.,
ch. ATCP 93 or other administrative rules but not related to a petroleum product discharge under this chapter;
NR 747.30(2)(d)4.
4. Costs associated with loss of interest or dividends, or interest costs from a loan other than one for the remediation; and
NR 747.30(2)(e)3.
3. Costs associated with the abandonment of wells not related to the remedial action.
NR 747.30(2)(f)1.
1. Costs, other than costs for compensating third parties for bodily injury and property damage, which the department determines to be unreasonable or unnecessary to carry out the remedial action activities as specified in the approved remedial action plan;
NR 747.30(2)(f)2.
2. Costs associated with third-party actions by adjoining property owners for the installation of monitoring wells or other cleanup-related items unless a court judgment has been obtained;
NR 747.30(2)(f)3.
3. Costs associated with third-party damages from a discharge originating from an aboveground storage tank;
NR 747.30(2)(f)5.
5. Any costs associated with an appeal of a determination specific to the scope of this chapter; and
NR 747.30(2)(f)6.
6. Other attorney fees including, but not limited to, legal advice, appeals, or other representation on behalf of the responsible party or agent.
NR 747.30(2)(g)
(g) Supervisory and management costs that the department determines to be unreasonable or unnecessary in carrying out the remedial action activities under this chapter:
NR 747.30(2)(g)1.
1. Supervisory or management costs when a municipality or company uses their own personnel or personnel from a wholly- or partially-owned subsidiary for remedial activities;
NR 747.30(2)(g)2.
2. Costs for supervisory or management activities conducted by owners or operators;
NR 747.30(2)(g)3.
3. Costs incurred by a responsible party associated with bid requirements or project administration such as consultant selection, monitoring or supervising subcontractors or consultants;
NR 747.30(2)(h)
(h) Any costs, excluding for an emergency action, incurred before a confirmed discharge is reported to the department.
NR 747.30 Note
Note: See s.
NR 747.305 for further ineligible costs associated with loans.
NR 747.30(2)(k)
(k) Costs determined by the department to be excessive, as defined by the usual and customary cost schedule periodically established by the department under
s. NR 747.325.
NR 747.30(2)(o)
(o) Costs for any work performed after submittal of the notice of completion of an investigation under
s. NR 747.62 (4) and prior to the department's issuance of a response to the responsible party and the consulting firm under
s. NR 747.62 (5).
NR 747.30(2)(p)
(p) Costs for any work performed more than 5 business days after the department issues a decision under
s. NR 747.62 (5) that an occurrence is subject to the public bidding process in
s. NR 747.68, if the work is conducted outside of that process.
NR 747.30(2)(q)
(q) Costs for any work that is performed after submittal of a written deferral notice under
s. NR 747.63 (5) (c) and prior to a departmental authorization to proceed with additional activities.
NR 747.30(2)(r)
(r) Costs for any unauthorized work performed more than 5 business days after the department issues a directive or notice under
s. NR 747.64 (1) about using the public bidding process in
s. NR 747.68.
NR 747.30(2)(s)
(s) Costs for any unauthorized services that are performed by any party other than a firm which submitted a bid under
s. NR 747.68 (2) and with which a contract is executed under
s. NR 747.69, if they are conducted after the qualified low bid is determined
under
s. NR 747.68 (3).
NR 747.30 Note
Note: For the purposes of pars. (o) to (s), costs for preparing or submitting a claim are eligible for reimbursement, regardless of when those costs are incurred.
NR 747.30(2)(u)
(u) Costs for unauthorized work performed more than 5 business days after the department issues a disqualification notice under
s. NR 747.70 (4) (d).
NR 747.30(2)(v)
(v) Costs for any work performed between the due date of any submittal required under this subchapter and the date a past-due submittal is actually submitted.
NR 747.30(2)(x)
(x) Costs incurred that exceed caps established by the department unless written department approval is received prior to performance of the corresponding work.
NR 747.30(3)(a)1.1. The costs in
par. (b) are considered to be grossly ineligible for reimbursement.
NR 747.30(3)(a)2.
2. An award for a claim which includes any costs in
par. (b) and which was prepared and submitted by an owner or operator or person owning a home oil tank system shall be reduced to exclude those costs, and shall then be further reduced by 50 percent of the total amount of those costs.
NR 747.30(3)(a)3.
3. A consultant who prepares a submitted claim that includes any costs in
par. (b) shall pay to the department an amount equal to 50 percent of the total amount of those costs, and the award for the claim shall be reduced to exclude those costs.
NR 747.30(3)(b)2.
2. Costs for cleanup resulting from spills from petroleum transportation equipment.
NR 747.30(3)(b)3.
3. Costs for investigations or remedial action activities conducted outside the state of Wisconsin.
NR 747.30(3)(b)4.
4. Costs associated with emptying, cleaning, or disposing of storage tank systems, and other costs associated with closing or removing any petroleum product storage tank system or home oil tank system after November 1, 1991 — unless the claimant has a contract for those services that was signed before November 1, 1991; or has a loan agreement, note, or commitment letter for a loan for the purposes of conducting those services, that was executed before November 1, 1991.
NR 747.30(3)(b)5.
5. Laboratory rush charges, unless related to an approved emergency action.
