AB50,881,6 1. All laborers, workers, mechanics, and truck drivers employed on the site of a project of public works that is subject to this section.

AB50,881,12 2. All laborers, workers, mechanics, and truck drivers employed in the manufacturing or furnishing of materials, articles, supplies, or equipment on the site of a project of public works that is subject to this section or from a facility dedicated exclusively, or nearly so, to a project of public works that is subject to this section by a contractor, subcontractor, agent, or other person performing any work on the site of the project.

AB50,881,20 (b) A laborer, worker, mechanic, or truck driver who is employed to process, manufacture, pick up, or deliver materials or products from a commercial establishment that has a fixed place of business from which the establishment supplies processed or manufactured materials or products or from a facility that is not dedicated exclusively, or nearly so, to a project of public works that is subject to this section is not entitled to receive the prevailing wage rate determined under sub. (3) or to receive at least 1.5 times his or her hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor unless any of the following applies:

AB50,882,2 1. The laborer, worker, mechanic, or truck driver is employed to go to the source of mineral aggregate such as sand, gravel, or stone and deliver that mineral aggregate to the site of a project of public works that is subject to this section by depositing the material directly in final place, from the transporting vehicle or through spreaders from the transporting vehicle.

AB50,882,6 2. The laborer, worker, mechanic, or truck driver is employed to go to the site of a project that is subject to this section, pick up excavated material or spoil from the site of the project of public works, and transport that excavated material or spoil away from the site of the project.

AB50,882,9 (c) A person that is subject to this section shall pay a truck driver who is an owner-operator of a truck separately for his or her work and for the use of his or her truck.

AB50,883,2 (3) Investigation; determination. (a) Before a state agency issues a request for bids for any work to which this section applies, the state agency having the authority to prescribe the specifications shall apply to the department to determine the prevailing wage rate for each trade or occupation required in the work under contemplation in the area in which the work is to be done. The department shall conduct investigations and hold public hearings as necessary to define the trades or occupations that are commonly employed on projects that are subject to this section and to inform itself of the prevailing wage rates in all areas of the state for those trades or occupations, in order to determine the prevailing wage rate for each trade or occupation. The department shall issue its determination within 30 days after receiving the request and shall file the determination with the requesting state agency. A state agency that has contracted for a project of public works subject to this section shall post the prevailing wage rates determined by the department, the prevailing hours of labor, and the provisions of subs. (2) and (6m) in at least one conspicuous place on the site of the project that is easily accessible by employees working on the project.

AB50,883,9 (am) The department shall, by January 1 of each year, compile the prevailing wage rates for each trade or occupation in each area. The compilation shall, in addition to the current prevailing wage rates, include future prevailing wage rates when those prevailing wage rates can be determined for any trade or occupation in any area and shall specify the effective date of those future prevailing wage rates. If a project of public works extends into more than one area, the department shall determine only one standard of prevailing wage rates for the entire project.

AB50,883,18 (ar) In determining prevailing wage rates under par. (a) or (am), the department may not use data from projects that are subject to this section, s. 66.0903, 103.50, or 229.8275, or 40 USC 3142 unless the department determines that there is insufficient wage data in the area to determine those prevailing wage rates, in which case the department may use data from projects that are subject to this section, s. 66.0903, 103.50, or 229.8275, or 40 USC 3142. In determining prevailing wage rates under par. (a) or (am), the department may not use data from any construction work performed by a state agency or a local governmental unit, as defined in s. 66.0903 (1) (d).

AB50,884,4 (b) Any person may request a recalculation of any portion of an initial determination within 30 days after the initial determination date if the person submits evidence with the request showing that the prevailing wage rate for any given trade or occupation included in the initial determination does not represent the prevailing wage rate for that trade or occupation in the area. The evidence shall include wage rate information reflecting work performed by individuals working in the contested trade or occupation in the area during the current survey period. The department shall affirm or modify the initial determination within 15 days after the date on which the department receives the request for recalculation.

AB50,884,18 (c) In addition to the recalculation under par. (b), the state agency that requested the determination under this subsection may request a review of any portion of a determination within 30 days after the date of issuance of the determination if the state agency submits evidence with the request showing that the prevailing wage rate for any given trade or occupation included in the determination does not represent the prevailing wage rate for that trade or occupation in the city, village, or town in which the proposed project of public works is located. That evidence shall include wage rate information for the contested trade or occupation on at least 3 similar projects located in the city, village, or town where the proposed project of public works is located on which some work has been performed during the current survey period and that were considered by the department in issuing its most recent compilation under par. (am). The department shall affirm or modify the determination within 15 days after the date on which the department receives the request for review.

AB50,884,19 (3g) Nonapplicability. This section does not apply to any of the following:

AB50,884,22 (a) A single-trade project of public works for which the estimated project cost of completion is less than $48,000 or a multiple-trade project of public works for which the estimated project cost of completion is less than $100,000.

AB50,885,3 (b) Work performed on a project of public works for which the state or the state agency contracting for the project is not required to compensate any contractor, subcontractor, contractor’s or subcontractor’s agent, or individual for performing the work.

AB50,885,5 (c) Minor service or maintenance work, warranty work, or work under a supply and installation contract.

AB50,885,6 (f) A public highway, street, or bridge project.

AB50,885,9 (g) A project of public works involving the erection, construction, repair, remodeling, or demolition of a residential property containing 2 dwelling units or less.

AB50,885,14 (h) A road, street, bridge, sanitary sewer, or water main project that is a part of a development in which not less than 90 percent of the lots contain or will contain 2 dwelling units or less, as determined by the local governmental unit at the time of approval of the development, and that, on completion, is acquired by, or dedicated to, the state for ownership or maintenance by the state.

AB50,885,22 (4r) Compliance. (a) When the department finds that a state agency has not requested a determination under sub. (3) (a) or that a state agency, contractor, or subcontractor has not physically incorporated a determination into a contract or subcontract as required under sub. (2) or has not notified a minor subcontractor of a determination in the manner prescribed by the department by rule promulgated under sub. (2), the department shall notify the state agency, contractor, or subcontractor of the noncompliance and shall file the determination with the state agency, contractor, or subcontractor within 30 days after the notice.

AB50,886,4 (b) Upon completion of a project of public works and before receiving final payment for his or her work on the project, each agent or subcontractor shall furnish the contractor with an affidavit stating that the agent or subcontractor has complied fully with the requirements of this section. A contractor may not authorize final payment until the affidavit is filed in proper form and order.

AB50,886,18 (c) Upon completion of a project of public works and before receiving final payment for his or her work on the project, each contractor shall file with the state agency authorizing the work an affidavit stating that the contractor has complied fully with the requirements of this section and that the contractor has received an affidavit under par. (b) from each of the contractor’s agents and subcontractors. A state agency may not authorize a final payment until the affidavit is filed in proper form and order. If a state agency authorizes a final payment before an affidavit is filed in proper form and order or if the department determines, based on the greater weight of the credible evidence, that any person performing the work specified in sub. (2m) has been or may have been paid less than the prevailing wage rate or less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor and requests that the state agency withhold all or part of the final payment, but the state agency fails to do so, the state agency is liable for all back wages payable up to the amount of the final payment.

AB50,887,2 (5) Records; inspection; enforcement. (a) Each contractor, subcontractor, or contractor’s or subcontractor’s agent that performs work on a project of public works that is subject to this section shall keep full and accurate records clearly indicating the name and trade or occupation of every individual performing the work described in sub. (2m) and an accurate record of the number of hours worked by each of those individuals and the actual wages paid for the hours worked.

AB50,887,13 (b) The department shall enforce this section. The department may demand and examine, and every contractor, subcontractor, and contractor’s and subcontractor’s agent shall keep, and furnish upon request by the department, copies of payrolls and other records and information relating to the wages paid to individuals performing the work described in sub. (2m) for work to which this section applies. The department may inspect records in the manner provided in this chapter. Every contractor, subcontractor, or agent performing work on a project of public works that is subject to this section is subject to the requirements of this chapter relating to the examination of records. Section 111.322 (2m) applies to discharge and other discriminatory acts arising in connection with any proceeding under this section.

AB50,888,4 (c) If requested by any person, the department shall inspect the payroll records of any contractor, subcontractor, or agent performing work on a project of public works that is subject to this section as provided in this paragraph to ensure compliance with this section. On receipt of such a request, the department shall request that the contractor, subcontractor, or agent submit to the department a certified record of the information specified in par. (a), other than personally identifiable information relating to an employee of the contractor, subcontractor, or agent, for no longer than a 4-week period. The department may request a contractor, subcontractor, or agent to submit those records no more than once per calendar quarter for each project of public works on which the contractor, subcontractor, or agent is performing work. The department may not charge a requester a fee for obtaining that information. Certified records submitted to the department under this paragraph are open for public inspection and copying under s. 19.35 (1).

AB50,888,11 (6m) Liability and penalties. (ag) 1. A contractor, subcontractor, or contractor’s or subcontractor’s agent who fails to pay the prevailing wage rate determined by the department under sub. (3) or who pays less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor is liable to any affected employee in the amount of his or her unpaid wages or his or her unpaid overtime compensation and in an additional amount as liquidated damages as provided in subd. 2. or 3., whichever is applicable.

AB50,888,20 2. If the department determines upon inspection under sub. (5) (b) or (c) that a contractor, subcontractor, or contractor’s or subcontractor’s agent has failed to pay the prevailing wage rate determined by the department under sub. (3) or has paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor, the department shall order the contractor to pay to any affected employee the amount of his or her unpaid wages or his or her unpaid overtime compensation and an additional amount equal to 100 percent of the amount of those unpaid wages or that unpaid overtime compensation as liquidated damages within a period specified by the department in the order.

AB50,889,9 3. In addition to or in lieu of recovering the liability specified in subd. 1. as provided in subd. 2., any employee for and on behalf of that employee and other employees similarly situated may commence an action to recover that liability in any court of competent jurisdiction. If the court finds that a contractor, subcontractor, or contractor’s or subcontractor’s agent has failed to pay the prevailing wage rate determined by the department under sub. (3) or has paid less than 1.5 times the hourly basic rate of pay for all hours worked in excess of the prevailing hours of labor, the court shall order the contractor, subcontractor, or agent to pay to any affected employee the amount of his or her unpaid wages or his or her unpaid overtime compensation and an additional amount equal to 100 percent of the amount of those unpaid wages or that unpaid overtime compensation as liquidated damages.

AB50,889,14 5. No employee may be a party plaintiff to an action under subd. 3. unless the employee consents in writing to become a party and the consent is filed in the court in which the action is brought. Notwithstanding s. 814.04 (1), the court shall, in addition to any judgment awarded to the plaintiff, allow reasonable attorney fees and costs to be paid by the defendant.

AB50,889,18 (am) Except as provided in pars. (b), (d), and (f), any contractor, subcontractor, or contractor’s or subcontractor’s agent who violates this section may be fined not more than $200 or imprisoned for not more than 6 months or both. Each day that a violation continues is a separate offense.